e10vq
Table of Contents

 
 
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
FORM 10-Q
 
     
þ   QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the quarterly period ended March 31, 2011
OR
     
o   TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the transition period from                      to                     
 
Commission file number 1-8267
EMCOR Group, Inc.
(Exact Name of Registrant as Specified in Its Charter)
     
Delaware   11-2125338
     
(State or Other Jurisdiction of Incorporation or
Organization)
  (I.R.S. Employer Identification
Number)
     
301 Merritt Seven    
Norwalk, Connecticut   06851-1092
     
(Address of Principal Executive Offices)   (Zip Code)
(203) 849-7800
(Registrant’s Telephone Number, Including Area Code)
N/A
(Former Name, Former Address and Former Fiscal Year, if Changed Since Last Report)
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes þ No o
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (Section 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes þ No o
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.
             
Large accelerated filer þ   Accelerated filer o   Non-accelerated filer o   Smaller reporting company o
        (Do not check if a smaller reporting company)    
Indicate by check mark whether the registrant is a shell company (as defined by Rule 12b-2 of the Exchange Act). Yes o No þ
Applicable Only To Corporate Issuers
Number of shares of Common Stock outstanding as of the close of business on April 25, 2011: 66,845,501 shares.
 
 

 

 


 

EMCOR Group, Inc.
INDEX
         
    Page No.  
 
       
       
 
       
       
 
       
    1  
 
       
    3  
 
       
    4  
 
       
    5  
 
       
    6  
 
       
    15  
 
       
    27  
 
       
    28  
 
       
       
 
       
    28  
 
       
    28  
 
       
 EX-31.1
 EX-31.2
 EX-32.1
 EX-32.2
 EX-101 INSTANCE DOCUMENT
 EX-101 SCHEMA DOCUMENT
 EX-101 CALCULATION LINKBASE DOCUMENT
 EX-101 LABELS LINKBASE DOCUMENT
 EX-101 PRESENTATION LINKBASE DOCUMENT
 EX-101 DEFINITION LINKBASE DOCUMENT

 

 


Table of Contents

PART I. — FINANCIAL INFORMATION.
ITEM 1.  
FINANCIAL STATEMENTS.
EMCOR Group, Inc. and Subsidiaries
CONDENSED CONSOLIDATED BALANCE SHEETS
(In thousands)
                 
    March 31,     December 31,  
    2011     2010  
    (Unaudited)        
ASSETS
               
Current assets:
               
Cash and cash equivalents
  $ 631,984     $ 710,836  
Accounts receivable, net
    1,103,195       1,090,927  
Costs and estimated earnings in excess of billings on uncompleted contracts
    111,858       88,253  
Inventories
    38,035       32,778  
Prepaid expenses and other
    56,799       57,373  
 
           
 
               
Total current assets
    1,941,871       1,980,167  
 
               
Investments, notes and other long-term receivables
    5,767       6,211  
 
               
Property, plant and equipment, net
    88,549       88,615  
 
               
Goodwill
    426,688       406,804  
 
               
Identifiable intangible assets, net
    259,401       245,089  
 
               
Other assets
    27,737       28,656  
 
           
 
               
Total assets
  $ 2,750,013     $ 2,755,542  
 
           
See Notes to Condensed Consolidated Financial Statements.

 

1


Table of Contents

EMCOR Group, Inc. and Subsidiaries
CONDENSED CONSOLIDATED BALANCE SHEETS
(In thousands, except share and per share data)
                 
    March 31,     December 31,  
    2011     2010  
    (Unaudited)        
 
               
LIABILITIES AND EQUITY
               
 
               
Current liabilities:
               
Borrowings under revolving credit facility
  $     $  
Current maturities of long-term debt and capital lease obligations
    478       489  
Accounts payable
    392,524       416,715  
Billings in excess of costs and estimated earnings on uncompleted contracts
    458,405       456,690  
Accrued payroll and benefits
    164,141       192,407  
Other accrued expenses and liabilities
    171,906       166,398  
 
           
 
               
Total current liabilities
    1,187,454       1,232,699  
 
               
Borrowings under revolving credit facility
    150,000       150,000  
 
               
Long-term debt and capital lease obligations
    1,426       1,184  
 
               
Other long-term obligations
    217,623       208,814  
 
           
 
               
Total liabilities
    1,556,503       1,592,697  
 
           
 
               
Equity:
               
EMCOR Group, Inc. stockholders’ equity:
               
Preferred stock, $0.01 par value, 1,000,000 shares authorized, zero issued and outstanding
           
Common stock, $0.01 par value, 200,000,000 shares authorized, 69,150,775 and 68,954,426 shares issued, respectively
    692       690  
Capital surplus
    432,052       427,613  
Accumulated other comprehensive loss
    (40,370 )     (42,411 )
Retained earnings
    807,170       782,576  
Treasury stock, at cost 2,316,461 and 2,293,875 shares, respectively
    (16,718 )     (15,525 )
 
           
 
               
Total EMCOR Group, Inc. stockholders’ equity
    1,182,826       1,152,943  
 
               
Noncontrolling interests
    10,684       9,902  
 
           
 
               
Total equity
    1,193,510       1,162,845  
 
           
 
               
Total liabilities and equity
  $ 2,750,013     $ 2,755,542  
 
           
See Notes to Condensed Consolidated Financial Statements.

 

2


Table of Contents

EMCOR Group, Inc. and Subsidiaries
CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS
(In thousands, except per share data)(Unaudited)
                 
Three months ended March 31,   2011     2010  
 
 
Revenues
  $ 1,312,231     $ 1,212,212  
Cost of sales
    1,149,261       1,047,096  
 
           
Gross profit
    162,970       165,116  
Selling, general and administrative expenses
    119,671       122,797  
Restructuring expenses
    961        
 
           
 
               
Operating income
    42,338       42,319  
Interest expense
    (2,746 )     (3,123 )
Interest income
    562       732  
 
           
Income before income taxes
    40,154       39,928  
Income tax provision
    14,778       17,511  
 
           
Net income including noncontrolling interests
    25,376       22,417  
Less: Net income attributable to noncontrolling interests
    (782 )     (600 )
 
           
Net income attributable to EMCOR Group, Inc.
  $ 24,594     $ 21,817  
 
           
 
               
Basic earnings per common share:
               
Net income attributable to EMCOR Group, Inc. common stockholders
  $ 0.37     $ 0.33  
 
           
 
               
Diluted earnings per common share:
               
Net income attributable to EMCOR Group, Inc. common stockholders
  $ 0.36     $ 0.32  
 
           
See Notes to Condensed Consolidated Financial Statements.

 

3


Table of Contents

EMCOR Group, Inc. and Subsidiaries
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS
(In thousands)(Unaudited)
                 
Three months ended March 31,   2011     2010  
 
 
Cash flows from operating activities:
               
Net income including noncontrolling interests
  $ 25,376     $ 22,417  
Depreciation and amortization
    6,232       6,297  
Amortization of identifiable intangible assets
    5,374       3,808  
Deferred income taxes
    7,753       11,801  
Gain on sale of equity investments
          (4,470 )
Excess tax benefits from share-based compensation
    (536 )      
Equity income from unconsolidated entities
    (190 )     (305 )
Other non-cash items
    1,826       1,852  
Distributions from unconsolidated entities
    520       866  
Changes in operating assets and liabilities
    (82,726 )     (115,332 )
 
           
Net cash used in operating activities
    (36,371 )     (73,066 )
 
           
 
               
Cash flows from investing activities:
               
Payments for acquisitions of businesses, identifiable intangible assets and related earn-out agreements
    (42,428 )     (10,826 )
Proceeds from sale of equity investments
          17,632  
Proceeds from sale of property, plant and equipment
    173       170  
Purchase of property, plant and equipment
    (4,517 )     (3,489 )
 
           
Net cash (used in) provided by investing activities
    (46,772 )     3,487  
 
           
 
               
Cash flows from financing activities:
               
Proceeds from revolving credit facility
          150,000  
Repayments of long-term debt and debt issuance costs
    (6 )     (200,806 )
Repayments of capital lease obligations
    (157 )     (116 )
Proceeds from exercise of stock options
    729        
Issuance of common stock under employee stock purchase plan
    579       587  
Distributions to noncontrolling interests
          (300 )
Excess tax benefits from share-based compensation
    536        
 
           
Net cash provided by (used in) financing activities
    1,681       (50,635 )
 
           
Effect of exchange rate changes on cash and cash equivalents
    2,610       (6,200 )
 
           
Decrease in cash and cash equivalents
    (78,852 )     (126,414 )
Cash and cash equivalents at beginning of year
    710,836       726,975  
 
           
Cash and cash equivalents at end of period
  $ 631,984     $ 600,561  
 
           
 
               
Supplemental cash flow information:
               
Cash paid for:
               
Interest
  $ 2,175     $ 1,833  
Income taxes
  $ 14,713     $ 17,720  
Non-cash financing activities:
               
Assets acquired under capital lease obligations
  $ 353     $  
Contingent purchase price accrued
  $     $ 614  
See Notes to Condensed Consolidated Financial Statements.

 

4


Table of Contents

EMCOR Group, Inc. and Subsidiaries
CONDENSED CONSOLIDATED STATEMENTS OF EQUITY
AND COMPREHENSIVE INCOME
(In thousands)(Unaudited)
                                                                 
                    EMCOR Group, Inc. Stockholders        
                                    Accumulated                    
                                    other                    
            Comprehensive     Common     Capital     comprehensive     Retained     Treasury     Noncontrolling  
    Total     income     stock     surplus     (loss) income (1)     earnings     stock     interests  
 
                                                               
Balance, January 1, 2010
  $ 1,226,466             $ 687     $ 416,267     $ (52,699 )   $ 869,267     $ (15,451 )   $ 8,395  
Net income including noncontrolling interests
    22,417     $ 22,417                         21,817             600  
Foreign currency translation adjustments
    1,808       1,808                   1,808                    
Pension adjustment, net of tax of $0.4 million
    922       922                   922                    
Deferred gain on cash flow hedge, net of tax of $0.1 million
    104       104                   104                    
 
                                                             
Comprehensive income
            25,251                                                  
Less : Net income attributable to noncontrolling interests
            (600 )                                                
 
                                                             
Comprehensive income attributable to EMCOR
          $ 24,651                                                  
 
                                                             
Treasury stock, at cost (2)
    (875 )                                     (875 )      
Common stock issued under share-based compensation plans (3)
                  1       (1 )                        
Common stock issued under employee stock purchase plan
    587                     587                          
Distributions to noncontrolling interests
    (300 )                                           (300 )
Share-based compensation expense
    1,303                     1,303                          
 
                                               
Balance, March 31, 2010
  $ 1,252,432             $ 688     $ 418,156     $ (49,865 )   $ 891,084     $ (16,326 )   $ 8,695  
 
                                                 
 
                                                               
Balance, January 1, 2011
  $ 1,162,845             $ 690     $ 427,613     $ (42,411 )   $ 782,576     $ (15,525 )   $ 9,902  
Net income including noncontrolling interests
    25,376     $ 25,376                         24,594             782  
Foreign currency translation adjustments
    1,720       1,720                   1,720                    
Pension adjustment, net of tax of $0.1 million
    321       321                   321                    
 
                                                             
Comprehensive income
            27,417                                                  
Less : Net income attributable to noncontrolling interests
            (782 )                                                
 
                                                             
Comprehensive income attributable to EMCOR
          $ 26,635                                                  
 
                                                             
Treasury stock, at cost (2)
    (1,255 )                                     (1,255 )      
Common stock issued under share-based compensation plans (3)
    2,420               2       2,356                   62        
Common stock issued under employee stock purchase plan
    579                     579                          
Share-based compensation expense
    1,504                     1,504                          
 
                                               
Balance, March 31, 2011
  $ 1,193,510             $ 692     $ 432,052     $ (40,370 )   $ 807,170     $ (16,718 )   $ 10,684  
 
                                                 
     
(1)  
Represents cumulative foreign currency translation adjustments, pension liability adjustments and deferred gain on interest rate swap.
 
(2)  
Represents value of shares of common stock withheld by EMCOR for income tax withholding requirements upon the issuance of shares in respect of restricted stock units.
 
(3)  
Includes the tax benefit associated with share-based compensation of $0.8 million and zero for the three months March 31, 2011 and 2010, respectively.
See Notes to Condensed Consolidated Financial Statements.

 

5


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 1 Basis of Presentation
The accompanying condensed consolidated financial statements have been prepared without audit, pursuant to the interim period reporting requirements of Form 10-Q. Consequently, certain information and note disclosures normally included in financial statements prepared in accordance with accounting principles generally accepted in the United States have been condensed or omitted. References to the “Company,” “EMCOR,” “we,” “us,” “our” and similar words refer to EMCOR Group, Inc. and its consolidated subsidiaries unless the context indicates otherwise. Readers of this report should refer to the consolidated financial statements and the notes thereto included in our latest Annual Report on Form 10-K filed with the Securities and Exchange Commission.
In our opinion, the accompanying unaudited condensed consolidated financial statements contain all adjustments (consisting only of a normal recurring nature) necessary to present fairly our financial position and the results of our operations. The results of operations for the three months ended March 31, 2011 are not necessarily indicative of the results to be expected for the year ending December 31, 2011.
Reclassification of prior year data has been made in the accompanying condensed consolidated financial statements where appropriate to conform to the current presentation.
NOTE 2 New Accounting Pronouncements
On January 1, 2011, we adopted the accounting pronouncement updating existing guidance on revenue recognition for arrangements with multiple deliverables. This guidance eliminates the requirement that all undelivered elements must have objective and reliable evidence of fair value before a company can recognize the portion of the consideration attributed to the delivered item. This may allow some companies to recognize revenue on transactions that involve multiple deliverables earlier than under previous requirements. We have determined that the adoption of the pronouncement did not have any effect on our financial position and/or results of operations, and we will review new and/or modified revenue arrangements after the adoption date to ensure compliance with this update.
On January 1, 2011, we adopted the accounting pronouncement updating existing guidance on business combinations, which clarifies that if comparative financial statements are presented, the pro forma revenue and earnings of the combined entity for the comparable prior reporting period should be reported as though the acquisition date for all business combinations that occurred during the current year had been as of the beginning of the comparable prior annual reporting period. We will consider the guidance in conjunction with future acquisitions.
On January 1, 2011, we adopted the accounting pronouncement updating existing guidance, which modifies the goodwill impairment test for reporting units with zero or negative carrying amounts. For reporting units with zero or negative carrying amounts, the second step of the goodwill impairment test must be performed if it appears more likely than not that a goodwill impairment exists. To make that determination, an entity should consider whether there are adverse qualitative factors indicating that an impairment may exist. We will consider the guidance in conjunction with our future goodwill impairment testing.
NOTE 3 Acquisitions of Businesses
On January 31, 2011, we acquired a company, and in 2010, we acquired two companies, each for an immaterial amount. The 2011 acquisition primarily provides mechanical construction services and has been included in our United States mechanical construction and facilities services segment. The 2010 acquisitions provide mobile mechanical services and government infrastructure contracting services and have been included in our United States facilities services reporting segment. We believe these acquisitions expand our service capabilities into new geographical and/or technical areas.

 

6


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 3 Acquisitions of Businesses — (continued)
During the first quarter of 2011, we finalized the purchase price allocation and the valuation of the identifiable intangible assets of a company acquired in 2010, resulting in an immaterial adjustment to the value of the related goodwill and identifiable intangible assets. The three acquired companies referred to in the immediately preceding paragraph were accounted for by the acquisition method, and the prices paid for them have been allocated to their respective assets and liabilities, based upon the estimated fair values of their respective assets and liabilities at the dates of their respective acquisitions.
NOTE 4 Earnings Per Share
Calculation of Basic and Diluted Earnings per Common Share
The following table summarizes our calculation of Basic and Diluted Earnings per Common Share (“EPS”) for the three months ended March 31, 2011 and 2010 (in thousands, except share and per share data):
                 
    For the  
    three months ended  
    March 31,  
    2011     2010  
Numerator:
               
Net income attributable to EMCOR Group, Inc. available to common stockholders
  $ 24,594     $ 21,817  
 
           
 
               
Denominator:
               
Weighted average shares outstanding used to compute basic earnings per common share
    66,808,687       66,316,105  
Effect of diluted securities — Share-based awards
    1,772,589       1,582,119  
 
           
 
               
Shares used to compute diluted earnings per common share
    68,581,276       67,898,224  
 
           
 
               
Basic earnings per common share:
               
Net income attributable to EMCOR Group, Inc. available to common stockholders
  $ 0.37     $ 0.33  
 
           
 
               
Diluted earnings per share:
               
Net income attributable to EMCOR Group, Inc. available to common stockholders
  $ 0.36     $ 0.32  
 
           
There were 140,096 and 311,347 anti-dilutive stock options that were excluded from the calculation of diluted EPS for the three months ended March 31, 2011 and 2010, respectively.
NOTE 5 Inventories
Inventories consist of the following amounts (in thousands):
                 
    March 31,     December 31,  
    2011     2010  
Raw materials and construction materials
  $ 20,466     $ 17,749  
Work in process
    17,569       15,029  
 
           
 
  $ 38,035     $ 32,778  
 
           

 

7


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 6 Investments, Notes and Other Long-Term Receivables
On January 8, 2010, a venture in which one of our subsidiaries had a 40% interest and which designs, constructs, owns, operates, leases and maintains facilities to produce chilled water for sale to customers for use in air conditioning commercial properties was sold to a third party. As a result of this sale, we received $17.7 million for our 40% interest and recognized a pretax gain of $4.5 million, which gain is included in our United States facilities services segment and classified as a component of “Cost of sales” on the Condensed Consolidated Statements of Operations.
NOTE 7 Debt
Debt in the accompanying Condensed Consolidated Balance Sheets consisted of the following amounts (in thousands):
                 
    March 31,     December 31,  
    2011     2010  
2010 Revolving Credit Facility
  $ 150,000     $ 150,000  
Capitalized lease obligations
    1,886       1,649  
Other
    18       24  
 
           
 
    151,904       151,673  
Less: current maturities
    478       489  
 
           
 
  $ 151,426     $ 151,184  
 
           
Credit Facilities
Until February 4, 2010, we had a revolving credit facility (the “Old Revolving Credit Facility”) as amended, which provided for a credit facility of $375.0 million. Effective February 4, 2010, we replaced the Old Revolving Credit Facility that was due to expire October 17, 2010 with an amended and restated $550.0 million revolving credit facility (the “2010 Revolving Credit Facility”). The 2010 Revolving Credit Facility expires in February 2013. It permits us to increase our borrowing to $650.0 million if additional lenders are identified and/or existing lenders are willing to increase their current commitments. We may allocate up to $175.0 million of the borrowing capacity under the 2010 Revolving Credit Facility to letters of credit, which amount compares to $125.0 million under the Old Revolving Credit Facility. The 2010 Revolving Credit Facility is guaranteed by certain of our direct and indirect subsidiaries and is secured by substantially all of our assets and most of the assets of most of our subsidiaries. The 2010 Revolving Credit Facility contains various covenants requiring, among other things, maintenance of certain financial ratios and certain restrictions with respect to payment of dividends, common stock repurchases, investments, acquisitions, indebtedness and capital expenditures. A commitment fee of 0.5% is payable on the average daily unused amount of the 2010 Revolving Credit Facility. Borrowings under the 2010 Revolving Credit Facility bear interest at (1) a rate which is the prime commercial lending rate announced by Bank of Montreal from time to time (3.25% at March 31, 2011) plus 1.75% to 2.25%, based on certain financial tests or (2) United States dollar LIBOR (0.25% at March 31, 2011) plus 2.75% to 3.25%, based on certain financial tests. The interest rate in effect at March 31, 2011 was 3.00%. Letter of credit fees issued under this facility range from 2.75% to 3.25% of the respective face amounts of the letters of credit issued and are charged based on certain financial tests. We capitalized approximately $6.0 million of debt issuance costs associated with the 2010 Revolving Credit Facility. This amount is being amortized over the life of the facility and is included as part of interest expense. In connection with the termination of the Old Revolving Credit Facility, less than $0.1 million was attributable to the acceleration of amortization of debt issuance costs and was recorded as part of interest expense. As of March 31, 2011 and December 31, 2010, we had approximately $89.3 million and $82.4 million of letters of credit outstanding, respectively. We have borrowings of $150.0 million outstanding under the 2010 Revolving Credit Facility at March 31, 2011, which may remain outstanding at our discretion until the 2010 Revolving Credit Facility expires.

 

8


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 7 Debt — (continued)
Term Loan
On September 19, 2007, we entered into an agreement providing for a $300.0 million term loan (“Term Loan”). The proceeds of the Term Loan were used to pay a portion of the consideration for an acquisition and costs and expenses incident thereto. In connection with the closing of the 2010 Revolving Credit Facility, we proceeded to borrow $150.0 million under this facility and used the proceeds along with cash on hand to prepay on February 4, 2010 all indebtedness outstanding under the Term Loan. In connection with this prepayment, $0.6 million was attributable to the acceleration of amortization of debt issuance costs associated with the Term Loan and was recorded as part of interest expense.
NOTE 8 Derivative Instrument and Hedging Activity
On January 27, 2009, we entered into an interest rate swap agreement (the “Swap Agreement”), which hedges the interest rate risk on our variable rate debt. The Swap Agreement matured in October 2010 and was used to manage the variable interest rate of our borrowings and related overall cost of borrowing. We mitigated the risk of counterparty nonperformance by choosing as our counterparty a major reputable financial institution with an investment grade credit rating.
The derivative was recognized as either an asset or liability on our Condensed Consolidated Balance Sheets with measurement at fair value, and changes in the fair value of the derivative instrument were reported in either net income, included as part of interest expense, or other comprehensive income, depending on the designated use of the derivative and whether or not it met the criteria for hedge accounting. The fair value of this instrument reflected the net amount required to settle the position. The accounting for gains and losses associated with changes in fair value of the derivative and the related effects on the condensed consolidated financial statements was subject to their hedge designation and whether they met effectiveness standards.
We paid a fixed rate on the Swap Agreement of 2.225% and received a floating rate of 30 day LIBOR on the notional amount. A portion of the interest rate swap had been designated as an effective cash flow hedge, whereby changes in the cash flows from the swap perfectly offset the changes in the cash flows associated with the floating rate of interest (see Note 7, “Debt”). The fair value of the interest rate swap at March 31, 2010 was a net liability of $1.0 million. This liability reflected the interest rate swap’s termination value as the credit value adjustment for counterparty nonperformance was immaterial. We had no obligation to post any collateral related to this derivative. The fair value of the interest rate swap was based upon the valuation technique known as the market standard methodology of netting the discounted future fixed cash flows and the discounted expected variable cash flows. The variable cash flows were based on an expectation of future interest rates (forward curves) derived from observable interest rate curves. In addition, we had incorporated a credit valuation adjustment into our calculation of fair value of the interest rate swap. This adjustment recognized both our nonperformance risk and the counterparty’s nonperformance risk. The net liability was included in “Other accrued expenses and liabilities” on our Condensed Consolidated Balance Sheet. Accumulated other comprehensive loss at March 31, 2010 included the accumulated loss, net of income taxes, on the cash flow hedge, of $0.5 million. For the three months ended March 31, 2010, we recognized $0.05 million of income associated with the ineffective portion of the interest rate swap as part of interest expense.
As of March 31, 2011 and December 31, 2010, we have no derivatives and/or hedging instruments outstanding.

 

9


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 9 Fair Value Measurements
We use a fair value hierarchy that prioritizes the inputs to valuation techniques used to measure fair value. The hierarchy, which gives the highest priority to quoted prices in active markets, is comprised of the following three levels:
Level 1 — Unadjusted quoted market prices in active markets for identical assets and liabilities.
Level 2 — Observable inputs, other than Level 1 inputs. Level 2 inputs would typically include quoted prices in markets that are not active or financial instruments for which all significant inputs are observable, either directly or indirectly.
Level 3 — Prices or valuations that require inputs that are both significant to the measurement and unobservable.
At March 31, 2011 and December 31, 2010, we had $153.6 million and $147.2 million, respectively, in money market funds, included within Cash and cash equivalents in the accompanying Condensed Consolidated Balance Sheets, which are Level 1 assets.
We believe that the carrying values of our financial instruments, which include accounts receivable and other financing commitments, approximate their fair values due primarily to their short-term maturities and low risk of counterparty default. The carrying value of our borrowings under the 2010 Revolving Credit Facility approximates the fair value due to the variable rate on such debt.
We measured the fair value of our derivative instrument on a recurring basis. At March 31, 2010, the $1.0 million fair value of the interest rate swap was determined using Level 2 inputs. There were no derivatives outstanding as of March 31, 2011 and December 31, 2010.
NOTE 10 Income Taxes
For the three months ended March 31, 2011 and 2010, our income tax provision was $14.8 million and $17.5 million, respectively, based on effective income tax rates, before discrete items, of 37.4% and 38.2%, respectively. The actual income tax rates for the three months ended March 31, 2011 and 2010, inclusive of discrete items, were 37.5% and 44.5%, respectively. The decrease in the 2011 income tax provision was primarily due to the reduction in income taxes attributable to discrete items and a change in the allocation of earnings among various jurisdictions.
As of March 31, 2011 and December 31, 2010, the amount of unrecognized income tax benefits for each period was $6.5 million (of which $4.2 million, if recognized, would favorably affect our effective income tax rate).
We recognized interest expense related to unrecognized income tax benefits in the income tax provision. As of March 31, 2011 and December 31, 2010, we had approximately $2.4 million and $2.3 million, respectively, of accrued interest related to unrecognized income tax benefits included as a liability on the Condensed Consolidated Balance Sheets, of which approximately a net of $0.1 million was recorded during each of the three months ended March 31, 2011 and 2010.
It is possible that approximately $1.1 million of unrecognized income tax benefits at March 31, 2011, primarily relating to uncertain tax positions attributable to compensation related accruals, will become recognized income tax benefits in the next twelve months due to the expiration of applicable statutes of limitations.

 

10


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 10 Income Taxes — (continued)
We file income tax returns with the Internal Revenue Service and various state, local and foreign jurisdictions. The Company is currently under examination by various states for the years 2004 through 2009. We are still subject to audit of our federal income tax returns by the Internal Revenue Service for the years 2007 through 2009.
NOTE 11 Common Stock
As of March 31, 2011 and December 31, 2010, 66,834,314 and 66,660,551 shares of our common stock were outstanding, respectively.
For the three months ended March 31, 2011 and 2010, 195,875 and 124,341 shares of common stock, respectively, were issued upon the exercise of stock options, upon the satisfaction of required conditions under certain of our share-based compensation plans and upon the grants of shares of common stock.
NOTE 12 Retirement Plans
Our United Kingdom subsidiary has a defined benefit pension plan covering all eligible employees (the “UK Plan”); however, no individual joining the company after October 31, 2001 may participate in the plan. On May 31, 2010, we curtailed the future accrual of benefits for active employees under this plan. As a result of this curtailment, we recognized a reduction of the projected benefit obligation and recorded a curtailment gain of $6.4 million, which will be amortized in the future through net periodic pension cost. This defined benefit pension plan was replaced by a defined contribution plan.
Components of Net Periodic Pension Benefit Cost
The components of net periodic pension benefit cost of the UK Plan for the three months ended March 31, 2011 and 2010 were as follows (in thousands):
                 
    For the three months ended  
    March 31,  
    2011     2010  
 
               
Service cost
  $     $ 883  
Interest cost
    3,329       3,480  
Expected return on plan assets
    (3,370 )     (2,984 )
Amortization of unrecognized loss
    389       1,234  
 
           
Net periodic pension benefit cost
  $ 348     $ 2,613  
 
           
Employer Contributions
For the three months ended March 31, 2011, our United Kingdom subsidiary contributed $1.5 million to its defined benefit pension plan. It anticipates contributing an additional $4.1 million during the remainder of 2011.

 

11


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 13 Commitments and Contingencies
Legal Matters
In our Form 10-K for the year ended December 31, 2010, we continued to report a claim made in an arbitration proceeding on March 14, 2003 by John Mowlem Construction plc (“Mowlem”) against our United Kingdom subsidiary, EMCOR Group (UK) plc (“EMCOR UK”), in connection with a subcontract EMCOR UK entered into with Mowlem with respect to a project for the United Kingdom Ministry of Defence. In the arbitration proceeding, Mowlem sought damages from EMCOR UK of approximately 38.5 million British pounds sterling (approximately $61.8 million) arising out of the electrical and mechanical engineering services EMCOR UK provided for the project. In that proceeding, EMCOR UK asserted a counterclaim for approximately 11.6 million British pounds sterling (approximately $18.6 million) for certain design, labor, and delay and disruption costs incurred by EMCOR UK in connection with the subcontract with Mowlem. On March 31, 2011, EMCOR UK, Mowlem, and Mowlem’s successors in interest settled all claims arising out of this matter, discontinued all related proceedings, and executed mutual releases.
NOTE 14 Segment Information
We have the following reportable segments which provide services associated with the design, integration, installation, start-up, operation and maintenance of various systems: (a) United States electrical construction and facilities services (involving systems for electrical power transmission and distribution; premises electrical and lighting systems; low-voltage systems, such as fire alarm, security and process control; voice and data communication; roadway and transit lighting; and fiber optic lines); (b) United States mechanical construction and facilities services (involving systems for heating, ventilation, air conditioning, refrigeration and clean-room process ventilation; fire protection; plumbing, process and high-purity piping; water and wastewater treatment and central plant heating and cooling); (c) United States facilities services; (d) Canada construction; (e) United Kingdom construction and facilities services; and (f) Other international construction and facilities services. The segment “United States facilities services” principally consists of those operations which provide a portfolio of services needed to support the operation and maintenance of customers’ facilities (industrial maintenance and services; outage services to utilities and industrial plants; commercial and government site-based operations and maintenance; military base operations support services; mobile maintenance and services; facilities management; installation and support for building systems; program development, management and maintenance for energy systems; technical consulting and diagnostic services; infrastructure and building projects for federal, state and local governmental agencies and bodies; small modification and retrofit projects; and retrofit projects to comply with clean air laws), which services are not generally related to customers’ construction programs, as well as industrial services operations, which primarily provide aftermarket maintenance and repair services, replacement parts and fabrication services for highly engineered shell and tube heat exchangers for refineries and the petrochemical industry. The Canada construction segment performs electrical construction and mechanical construction. The United Kingdom and Other international construction and facilities services segments perform electrical construction, mechanical construction and facilities services. Our “Other international construction and facilities services” segment consisted of our equity interest in a Middle East venture, which interest we sold in June 2010.

 

12


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 14 Segment Information — (continued)
The following tables present information about industry segments and geographic areas for the three months ended March 31, 2011 and 2010 (in thousands):
                 
    For the three months ended  
    March 31,  
    2011     2010  
Revenues from unrelated entities:
               
United States electrical construction and facilities services
  $ 268,532     $ 260,320  
United States mechanical construction and facilities services
    422,313       412,708  
United States facilities services
    449,521       346,840  
 
           
Total United States operations
    1,140,366       1,019,868  
Canada construction
    46,988       78,259  
United Kingdom construction and facilities services
    124,877       114,085  
Other international construction and facilities services
           
 
           
Total worldwide operations
  $ 1,312,231     $ 1,212,212  
 
           
 
               
Total revenues:
               
United States electrical construction and facilities services
  $ 269,722     $ 261,918  
United States mechanical construction and facilities services
    424,851       414,491  
United States facilities services
    453,192       351,250  
Less intersegment revenues
    (7,399 )     (7,791 )
 
           
Total United States operations
    1,140,366       1,019,868  
Canada construction
    46,988       78,259  
United Kingdom construction and facilities services
    124,877       114,085  
Other international construction and facilities services
           
 
           
Total worldwide operations
  $ 1,312,231     $ 1,212,212  
 
           

 

13


Table of Contents

EMCOR Group, Inc. and Subsidiaries
Notes to Condensed Consolidated Financial Statements (Unaudited)
NOTE 14 Segment Information — (continued)
                 
    For the three months ended  
    March 31,  
    2011     2010  
Operating income (loss):
               
United States electrical construction and facilities services
  $ 14,421     $ 9,220  
United States mechanical construction and facilities services
    23,296       24,818  
United States facilities services
    15,311       14,085  
 
           
Total United States operations
    53,028       48,123  
Canada construction
    501       3,321  
United Kingdom construction and facilities services
    2,620       3,235  
Other international construction and facilities services
          (1 )
Corporate administration
    (12,850 )     (12,359 )
Restructuring expenses
    (961 )      
 
           
Total worldwide operations
    42,338       42,319  
 
               
Other corporate items:
               
Interest expense
    (2,746 )     (3,123 )
Interest income
    562       732  
 
           
Income before income taxes
  $ 40,154     $ 39,928  
 
           
                 
    March 31,     December 31,  
    2011     2010  
Total assets:
               
United States electrical construction and facilities services
  $ 290,655     $ 295,091  
United States mechanical construction and facilities services
    640,291       577,299  
United States facilities services
    880,826       866,044  
 
           
Total United States operations
    1,811,772       1,738,434  
Canada construction
    97,789       103,000  
United Kingdom construction and facilities services
    218,287       201,620  
Other international construction and facilities services
           
Corporate administration
    622,165       712,488  
 
           
Total worldwide operations
  $ 2,750,013     $ 2,755,542  
 
           

 

14


Table of Contents

ITEM 2.  
MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS.
We are one of the largest electrical and mechanical construction and facilities services firms in the United States, Canada, the United Kingdom and in the world. We provide services to a broad range of commercial, industrial, utility and institutional customers through over 70 operating subsidiaries and joint venture entities. Our offices are located in the United States, Canada and the United Kingdom. In the Middle East, we previously carried on business through a venture, which we sold in June 2010.
Overview
The following table presents selected financial data for the three months ended March 31, 2011 and 2010 (in thousands, except percentages and per share data):
                 
    For the three months ended  
    March 31,  
    2011     2010  
Revenues
  $ 1,312,231     $ 1,212,212  
Revenues increase (decrease) from prior year
    8.3 %     (13.1 )%
Operating income
  $ 42,338     $ 42,319  
Operating income as a percentage of revenues
    3.2 %     3.5 %
Net income attributable to EMCOR Group, Inc.
  $ 24,594     $ 21,817  
Diluted earnings per common share
  $ 0.36     $ 0.32  
The results of our operations for the first quarter of 2011 reflect continued ability of our segments to perform profitably in an uncertain and difficult economic environment. Although overall revenues showed an increase, operating income remained consistent with 2010 levels, and operating margins (operating income as a percentage of revenues) decreased indicating the margin pressure our segments are experiencing in the marketplace. The increase in revenues for the 2011 first quarter, when compared to the prior year’s first quarter, was primarily attributable to: (a) higher organic revenues from our United States facilities services segment, particularly within our mobile mechanical services and industrial services operations, (b) revenues of $65.1 million attributable to companies acquired in 2011 and 2010, which are reported within our United States mechanical construction and facilities services and our United States facilities services segments, (c) higher revenues from our United Kingdom operations and (d) higher revenues from our United States electrical construction and facilities services segment. This increase in revenues was partially offset by a decrease in revenues from our Canadian operations. The decrease in operating margin was primarily a result of: (a) lower margins within our United States facilities services segment, primarily as a result of the recognition of a pretax gain of $4.5 million in the first quarter of 2010 from the sale of our interest in a venture, which gain is classified as a component of “Cost of sales” on the Condensed Consolidated Statements of Operations, and lower margins at our organic mobile mechanical operations, (b) lower margins at our international operations and (c) lower margins at our organic United States mechanical construction and facilities services segment. During the first three months of 2011, cash was used in operating activities, primarily due to changes in our working capital, including a reduction in accounts payable, a net decrease in the contract in progress accounts and a reduction in the accruals for payroll and benefits resulting from the payment of incentive compensation awards.
We completed one acquisition during the first quarter of 2011 for an immaterial amount. The results of the acquired company, which primarily provides mechanical construction services, have been included in our United States mechanical construction and facilities services segment; the acquired company expands our service capabilities into new geographical and technical areas. The acquisition is not material to our results of operations for the periods presented.

 

15


Table of Contents

Operating Segments
We have the following reportable segments which provide services associated with the design, integration, installation, start-up, operation and maintenance of various systems: (a) United States electrical construction and facilities services (involving systems for electrical power transmission and distribution; premises electrical and lighting systems; low-voltage systems, such as fire alarm, security and process control; voice and data communication; roadway and transit lighting; and fiber optic lines); (b) United States mechanical construction and facilities services (involving systems for heating, ventilation, air conditioning, refrigeration and clean-room process ventilation; fire protection; plumbing, process and high-purity piping; water and wastewater treatment and central plant heating and cooling); (c) United States facilities services; (d) Canada construction; (e) United Kingdom construction and facilities services; and (f) Other international construction and facilities services. The segment “United States facilities services” principally consists of those operations which provide a portfolio of services needed to support the operation and maintenance of customers’ facilities (industrial maintenance and services; outage services to utilities and industrial plants; commercial and government site-based operations and maintenance; military base operations support services; mobile maintenance and services; facilities management; installation and support for building systems; program development, management and maintenance for energy systems; technical consulting and diagnostic services; infrastructure and building projects for federal, state and local governmental agencies and bodies; small modification and retrofit projects; and retrofit projects to comply with clean air laws), which services are not generally related to customers’ construction programs, as well as industrial services operations, which primarily provide aftermarket maintenance and repair services, replacement parts and fabrication services for highly engineered shell and tube heat exchangers for refineries and the petrochemical industry. The Canada construction segment performs electrical construction and mechanical construction. The United Kingdom and Other international construction and facilities services segments perform electrical construction, mechanical construction and facilities services. Our “Other international construction and facilities services” segment consisted of our equity interest in a Middle East venture, which interest we sold in June 2010.
Results of Operations
Revenues
The following table presents our operating segment revenues from unrelated entities and their respective percentages of total revenues (in thousands, except for percentages):
                                 
    For the three months ended March 31,  
            % of           % of
    2011     Total   2010     Total
Revenues:
                               
United States electrical construction and facilities services
  $ 268,532       20 %   $ 260,320       21 %
United States mechanical construction and facilities services
    422,313       32 %     412,708       34 %
United States facilities services
    449,521       34 %     346,840       29 %
 
                           
Total United States operations
    1,140,366       87 %     1,019,868       84 %
Canada construction
    46,988       4 %     78,259       6 %
United Kingdom construction and facilities services
    124,877       10 %     114,085       9 %
Other international construction and facilities services
                       
 
                           
Total worldwide operations
  $ 1,312,231       100 %   $ 1,212,212       100 %
 
                           
As described below in more detail, our revenues for the three months ended March 31, 2011 increased to $1.31 billion compared to $1.21 billion of revenues for the three months ended March 31, 2010. This increase in revenues, excluding the effect of acquisitions, was primarily attributable to: (a) higher organic revenues from our United States facilities services segment, particularly within our mobile mechanical services and industrial services operations, (b) higher revenues from our United Kingdom operations and (c) higher revenues from our United States electrical construction and facilities services segment. The overall increase in revenues was also attributable to revenues of $65.1 million attributable to companies acquired in 2011 and 2010, which are reported within our United States mechanical construction and facilities services and our United States facilities services segments. The overall increase in revenues was partially offset by a decline in revenues from our Canada construction and organic United States mechanical construction and facilities services segments.

 

16


Table of Contents

Our backlog at March 31, 2011 was $3.57 billion compared to $3.29 billion of backlog at March 31, 2010. Our backlog was $3.42 billion at December 31, 2010. Backlog increases with awards of new contracts and decreases as we perform work on existing contracts. The increase in backlog at March 31, 2011, compared to such backlog at March 31, 2010, was primarily attributable to the acquisition of two companies, one in 2011 and the other in 2010, which are included in our United States mechanical construction and facilities services and United States facilities services segments. Organically, overall backlog decreased slightly year over year, primarily within our domestic construction and Canada construction segments, partially offset by an increase in the backlog of our United States facilities services and United Kingdom construction and facilities services segments. Backlog is not a term recognized under United States generally accepted accounting principles; however, it is a common measurement used in our industry. Backlog includes unrecognized revenues to be realized from uncompleted construction contracts plus unrecognized revenues expected to be realized over the remaining term of facilities services contracts. However, if the remaining term of a facilities services contract exceeds 12 months, the unrecognized revenues attributable to such contract included in backlog are limited to only the next 12 months of revenues.
Revenues of our United States electrical construction and facilities services segment were $268.5 million for the three months ended March 31, 2011, compared to revenues of $260.3 million for the three months ended March 31, 2010. The increase in revenues was primarily attributable to higher levels of work on commercial, water and wastewater, and healthcare construction projects. Notwithstanding the slight increase in revenues, we continue to show discipline in the current economic environment, in which customers continue to curtail and/or defer capital spending in most of our markets, and our decision to only accept work that we believe can be performed at a reasonable margin. This increase was partially offset by a decrease in revenues from hospitality construction projects, principally in the Las Vegas market, and transportation construction projects.
Revenues of our United States mechanical construction and facilities services segment for the three months ended March 31, 2011 were $422.3 million, a $9.6 million increase compared to revenues of $412.7 million for the three months ended March 31, 2010. The increase in revenues for the three months ended March 31, 2011, compared to the three months ended March 31, 2010, was primarily attributable to revenues of approximately $30.0 million from a company acquired in 2011, which primarily provides mechanical construction services, and an increase in revenues from healthcare and water and wastewater construction projects. This increase was partially offset by a decrease in revenues from commercial construction projects. The organic decline in revenues is a result of the continued reluctance of our customers to commit to capital expenditures and a very competitive marketplace where there are numerous bidders for any given project.
Our United States facilities services segment revenues for the three months ended March 31, 2011 increased by $102.7 million compared to the three months ended March 31, 2010. The increase in revenues was primarily attributable to: (a) revenues of approximately $35.1 million from companies acquired in 2010, which perform government infrastructure contracting services and mobile mechanical services, (b) revenues from the organic operations of our mobile mechanical service and (c) revenues from our industrial services operations, which has seen a resurgence in demand for its turnaround work and specialty call-out services at refinery and petrochemical facilities.
Our Canada construction segment revenues were $47.0 million for the three months ended March 31, 2011 compared to revenues of $78.3 million for the three months ended March 31, 2010. The decrease in revenues of $31.3 million for the three months ended March 31, 2011 was primarily attributable to a decline in revenues from industrial, including automotive, construction projects, as 2010 benefited from a significant project, which did not replicate itself in 2011, and healthcare construction projects. These decreases were partially offset by an increase of $2.5 million relating to the effect of favorable exchange rates for the Canadian dollar versus the United States dollar.
Our United Kingdom construction and facilities services segment revenues for the three months ended March 31, 2011 increased by $10.8 million compared to revenues for the three months ended March 31, 2010. The increase in revenues was attributable to its facilities services operations, principally in the commercial market, and an increase of $3.9 million relating to the effect of favorable exchange rates for the British pound versus the United States dollar, partially offset by a decrease in revenues from construction projects.
Other international construction and facilities services activities consisted of a venture in the Middle East. The results of the venture were accounted for under the equity method. In June 2010, we sold our equity interest in a Middle East venture to our partner in the venture.

 

17


Table of Contents

Cost of sales and Gross profit
The following table presents our cost of sales, gross profit (revenues less cost of sales) and gross profit margin (gross profit as a percentage of revenues) (in thousands, except for percentages):
                 
    For the three months ended  
    March 31,  
    2011     2010  
Cost of sales
  $ 1,149,261     $ 1,047,096  
Gross profit
  $ 162,970     $ 165,116  
Gross profit, as a percentage of revenues
    12.4 %     13.6 %
Our gross profit decreased by $2.1 million for the three months ended March 31, 2011 compared to the three months ended March 31, 2010. The decrease in gross profit was primarily attributable to lower margins across the majority of our business segments and lower volume at our Canada construction and organic United States mechanical construction and facilities services segments. In addition, gross profit for the three months ended March 31, 2010 was favorably impacted by: (a) an increase in gross profit contributed by our energy services operations within our United States facilities services segment, primarily as a result of the recognition of a pretax gain of $4.5 million from the sale of our interest in a venture, which gain is classified as a component of “Cost of sales” on the Condensed Consolidated Statements of Operations and (b) the favorable resolution of an uncertainty on a construction project at or nearing completion in the United Kingdom construction and facilities services segment. The overall decrease in gross profit for the three months ended March 31, 2011 was partially offset by: (a) companies acquired in 2011 and 2010 within our United States mechanical construction and facilities services and our United States facilities services segments, which contributed $5.5 million to gross profit, net of amortization expense of $1.2 million, (b) the favorable resolution of uncertainties on a completed institutional construction project in the United States electrical construction and facilities services segment and (c) the effect of favorable exchange rates for the British pound and the Canadian dollar versus the United States dollar.
Our gross profit margin was 12.4% and 13.6% for the three months ended March 31, 2011 and 2010, respectively. The decrease in gross profit margin for the three months ended March 31, 2011 was primarily the result of (a) lower gross profit margins at our United States facilities services segment, particularly in our energy services operations which benefited in the first quarter of 2010 from the recognition of a pretax gain of $4.5 million from the sale of our interest in a venture, as discussed above, and lower gross profit margins at our mobile mechanical operations, (b) lower gross profit margins at our United Kingdom construction and facilities services and our United States mechanical construction and facilities services segments, which both benefited in the first quarter of 2010 from the favorable resolution on project uncertainties, and (c) lower margins on new work performed. The decrease in gross profit margin for the three months ended March 31, 2011 was partially offset by higher gross profit margins at our United States electrical construction and facilities services segment, primarily as a result of the favorable resolution of uncertainties on a completed institutional construction project.
Selling, general and administrative expenses
The following table presents our selling, general and administrative expenses and selling, general and administrative expenses as a percentage of revenues (in thousands, except for percentages):
                 
    For the three months ended  
    March 31,  
    2011     2010  
Selling, general and administrative expenses
  $ 119,671     $ 122,797  
Selling, general and administrative expenses, as a percentage of revenues
    9.1 %     10.1 %
Our selling, general and administrative expenses for the three months ended March 31, 2011 decreased by $3.1 million to $119.7 million compared to $122.8 million for the three months ended March 31, 2010. Selling, general and administrative expenses as a percentage of revenues were 9.1% and 10.1% for the three months ended March 31, 2011. This decrease in selling, general and administrative expenses was primarily due to: (a) reduced employee costs, such as salaries, incentive compensation and employee benefits. The decreases were partially offset by the effect of exchange rates for the Canadian dollar and the British pound versus the United States dollar. In addition, the decreases in selling, general and administrative expenses for the three months ended March 31, 2011 were partially offset by $4.9 million of expenses directly related to companies acquired in 2011 and 2010, including amortization expense of $0.8 million, and (b) an increase in professional and legal fees. Selling, general and administrative expenses as a percentage of revenues decreased for the three months ended March 31, 2011 compared to the same period in 2010, primarily due to higher revenues and lower selling, general and administrative expenses.

 

18


Table of Contents

Restructuring expenses
Restructuring expenses were $1.0 million and zero, respectively, for the three months ended March 31, 2011 and 2010, respectively, which primarily related to employee severance obligations reported in our corporate headquarters. As of March 31, 2011, the balance of our severance obligations yet to be paid was $0.6 million, which is expected to be paid in 2011.
Operating income
The following table presents our operating income (loss) and operating income (loss) as a percentage of segment revenues from unrelated entities (in thousands, except for percentages):
                                 
    For the three months ended March 31,
            % of           % of
            Segment           Segment
    2011     Revenues   2010     Revenues
Operating income (loss):
                               
United States electrical construction and facilities services
  $ 14,421       5.4 %   $ 9,220       3.5 %
United States mechanical construction and facilities services
    23,296       5.5 %     24,818       6.0 %
United States facilities services
    15,311       3.4 %     14,085       4.1 %
 
                           
Total United States operations
    53,028       4.7 %     48,123       4.7 %
Canada construction
    501       1.1 %     3,321       4.2 %
United Kingdom construction and facilities services
    2,620       2.1 %     3,235       2.8 %
Other international construction and facilities services
                (1 )      
Corporate administration
    (12,850 )           (12,359 )      
Restructuring expenses
    (961 )                  
 
                           
Total worldwide operations
    42,338       3.2 %     42,319       3.5 %
 
                               
Other corporate items:
                               
Interest expense
    (2,746 )             (3,123 )        
Interest income
    562               732          
 
                           
Income before income taxes
  $ 40,154             $ 39,928          
 
                           
As described below in more detail, operating income was $42.3 million for both the three months ended March 31, 2011 and 2010. Operating margin was 3.2% for the three months ended March 31, 2011 compared to 3.5% for the three months ended March 31, 2010.
Our United States electrical construction and facilities services segment operating income for the three months ended March 31, 2011 was $14.4 million compared to operating income of $9.2 million for the three months ended March 31, 2010. The increase in operating income was primarily the result of the favorable resolution of an uncertainty associated with a completed institutional construction project. In addition, operating income for the three months ended March 31, 2011 benefited from lower selling, general and administrative expenses and higher gross profit from healthcare and water and wastewater construction projects. These increases were partially offset by a decrease in gross profit attributable to industrial construction projects. Selling, general and administrative expenses decreased for the three months ended March 31, 2011, compared to the same period in 2010, principally due to reduced employee costs, such as salaries, incentive compensation and employee benefits, partially attributable to reduced staff levels. The increase in operating margin for the three months ended March 31, 2011 was primarily the result of an increase in gross profit margin and a decrease in the ratio of selling, general and administrative expenses to revenues.

 

19


Table of Contents

Our United States mechanical construction and facilities services segment operating income for the three months ended March 31, 2011 was $23.3 million, a $1.5 million decrease compared to operating income of $24.8 million for the three months ended March 31, 2010. The decrease in operating income was primarily due to lower gross profit from industrial and commercial construction projects, as a result of the current economic slowdown and our selectivity in bidding on contracts. This decrease was partially offset by: (a) an increase in gross profit from healthcare and hospitality construction projects and (b) operating income of $0.4 million, net of amortization expense of $0.6 million, from a company acquired in 2011, which primarily provides mechanical construction services. Organic selling, general and administrative expenses decreased period over period, primarily due to reduced employee costs, such as salaries, incentive compensation and employee benefits. The decrease in operating margin for the three months ended March 31, 2011 was primarily the result of a reduction in gross profit margin.
Our United States facilities services segment operating income for the three months ended March 31, 2011 increased by $1.2 million compared to operating income for the three months ended March 31, 2010. The increase in operating income was primarily due to our industrial services operations, which has seen a resurgence in demand for its turnaround work and specialty call-out services at refinery and petrochemical facilities. In addition, companies we acquired in 2010, which perform mobile mechanical services and government infrastructure contracting services, contributed $0.2 million to operating income, net of amortization expense of $1.4 million. These increases were partially offset by a decrease in operating income from our energy services operations, which benefited in the first quarter of 2010 from the recognition of a pretax gain of $4.5 million from the sale of our interest in a venture, which is classified as a component of “Cost of sales” on the Condensed Consolidated Statements of Operations. Organic selling, general and administrative expenses for the three months ended March 31, 2011 decreased period over period, primarily due to reduced employee costs, such as incentive compensation and employee benefits. The decrease in operating margin for the three months ended March 31, 2011 was primarily the result of a reduction in gross profit margin.
Our Canada construction segment operating income was $0.5 million for the three months ended March 31, 2011 compared to operating income of $3.3 million for the three months ended March 31, 2010. This decrease in operating income was primarily attributable to a decrease in gross profit from industrial, including automotive, construction projects. The decrease in operating margin for the three months ended March 31, 2011 was primarily the result of an increase in the ratio of selling, general and administrative expense to revenues due to a decrease in revenues.
Our United Kingdom construction and facilities services segment operating income for the three months ended March 31, 2011 decreased by $0.6 million compared to operating income for the three months ended March 31, 2010. The decrease in operating income for the three months ended March 31, 2011, compared to the same period in 2010, was primarily attributable to a favorable resolution of uncertainties on a construction project at completion in the first quarter of 2010, and lower gross profit from its facilities services operations, partially offset by a decrease in the net periodic pension costs and selling, general and administrative expenses. The decrease in operating margin for the three months ended March 31, 2011 was primarily the result of a reduction in gross profit margin.
In June 2010, we sold our equity interest in a Middle East venture to our partner in the venture. The Other international construction and facilities services segment was breakeven for the three months ended March 31, 2010.
Our corporate administration expenses for the three months ended March 31, 2011 were $12.9 million compared to $12.4 million for the three months ended March 31, 2010. The increase in expenses was primarily due to an increase in professional fees.
Interest expense for the three months ended March 31, 2011 and 2010 was $2.7 million and $3.1 million, respectively. The reduction in interest expense was primarily due to the recognition of an expense in the first quarter of 2010 attributable to the acceleration of debt issuance costs associated with the early termination of the term loan and revolving credit facility. Interest income for the three months ended March 31, 2011 was $0.6 million compared to $0.7 million for the three months ended March 31, 2010. The decrease in interest income was primarily related to lower interest rates on our invested cash balances.
For the three months ended March 31, 2011 and 2010, our income tax provision was $14.8 million and $17.5 million, respectively, based on effective income tax rates, before discrete items, of 37.4% and 38.2%, respectively. The actual income tax rates for the three months ended March 31, 2011 and 2010, inclusive of discrete items, were 37.5% and 44.5%, respectively. The decrease in the 2011 income tax provision was primarily due to the reduction in income taxes attributable to discrete items and a change in the allocation of earnings among various jurisdictions.

 

20


Table of Contents

Liquidity and Capital Resources
The following table presents our net cash provided by (used in) operating activities, investing activities and financing activities (in thousands):
                 
    For the three months ended  
    March 31,  
    2011     2010  
Net cash used in operating activities
  $ (36,371 )   $ (73,066 )
Net cash (used in) provided by investing activities
  $ (46,772 )   $ 3,487  
Net cash provided by (used in) financing activities
  $ 1,681     $ (50,635 )
Effect of exchange rate changes on cash and cash equivalents
  $ 2,610     $ (6,200 )
Our consolidated cash balance decreased by approximately $78.9 million from $710.8 million at December 31, 2010 to $632.0 million at March 31, 2011. Net cash used in operating activities for the three months ended March 31, 2011 of $36.4 million, compared to $73.1 million of net cash used in operating activities for the three months ended March 31, 2010. The decrease in net cash used in operating activities was primarily due to changes in our working capital, including a net decrease in the contract in progress accounts, offset by a reduction in the payment of incentive compensation compared to the prior period. Net cash used in investing activities of $46.8 million for the three months ended March 31, 2011, compared to net cash provided by investing activities of $3.5 million for the three months ended March 31, 2010, was primarily due to a $32.1 million increase in payments for acquisitions of businesses and a $17.6 million decrease in proceeds from the sale of equity investments. Net cash provided by financing activities for the three months ended March 31, 2011 of $1.7 million, compared to $50.6 million of net cash used in financing activities for the three months ended March 31, 2010, was primarily attributable to repayment of our term loan and debt issuance costs, partially offset by borrowings under our new credit facility in the first quarter of 2010.
The following is a summary of material contractual obligations and other commercial commitments (in millions):
                                         
            Payments Due by Period  
            Less                    
Contractual           than     1-3     4-5     After  
Obligations   Total     1 year     years     years     5 years  
 
 
Revolving Credit Facility (including interest at 3.00%) (1)
  $ 158.5     $ 4.6     $ 153.9     $     $  
Capital lease obligations
    1.9       0.6       0.9       0.4        
Operating leases
    201.2       53.6       73.2       44.0       30.4  
Open purchase obligations (2)
    891.2       691.7       178.8       16.9       3.8  
Other long-term obligations (3)
    228.8       43.5       177.8       7.5        
Liabilities related to uncertain income tax positions
    9.0       1.4       0.3       6.1       1.2  
 
                             
Total Contractual Obligations
  $ 1,490.6     $ 795.4     $ 584.9     $ 74.9     $ 35.4  
 
                             
                                         
            Amount of Commitment Expiration by Period  
            Less                    
Other Commercial   Total     than     1-3     4-5     After  
Commitments   Committed     1 year     years     years     5 years  
 
                                       
Letters of credit
  $ 89.3     $ 89.3     $     $     $  
 
                             
(1)  
We classify these borrowings as long-term on our Condensed Consolidated Balance Sheets because of our intent to repay the amounts on a long-term basis. These amounts are outstanding at our discretion and are not payable until the 2010 Revolving Credit Facility expires in February 2013. As of March 31, 2011, there were borrowings of $150.0 million outstanding under the 2010 Revolving Credit Facility.
 
(2)  
Represents open purchase orders for material and subcontracting costs related to construction and service contracts. These purchase orders are not reflected in EMCOR’s Condensed Consolidated Balance Sheets and should not impact future cash flows, as amounts are expected to be recovered through customer billings.
 
(3)  
Represents primarily insurance related liabilities and liabilities for deferred income taxes, incentive compensation and earn-out arrangements, classified as other long-term liabilities in the Condensed Consolidated Balance Sheets. Cash payments for insurance related liabilities may be payable beyond three years, but it is not practical to estimate these payments. We provide funding to our defined benefit pension plans based on at least the minimum funding required by applicable regulations. In determining the minimum required funding, we utilize current actuarial assumptions and exchange rates to forecast estimates of amounts that may be payable for up to five years in the future. In our judgment, minimum funding estimates beyond a five year time horizon cannot be reliably estimated, and therefore, have not been included in the table.

 

21


Table of Contents

Until February 4, 2010, we had a revolving credit facility (the “Old Revolving Credit Facility”) as amended, which provided for a credit facility of $375.0 million. Effective February 4, 2010, we replaced the Old Revolving Credit Facility that was due to expire October 17, 2010 with an amended and restated $550.0 million revolving credit facility (the “2010 Revolving Credit Facility”). The 2010 Revolving Credit Facility expires in February 2013. It permits us to increase our borrowing to $650.0 million if additional lenders are identified and/or existing lenders are willing to increase their current commitments. We may allocate up to $175.0 million of the borrowing capacity under the 2010 Revolving Credit Facility to letters of credit, which amount compares to $125.0 million under the Old Revolving Credit Facility. The 2010 Revolving Credit Facility is guaranteed by certain of our direct and indirect subsidiaries and is secured by substantially all of our assets and most of the assets of most of our subsidiaries. The 2010 Revolving Credit Facility contains various covenants requiring, among other things, maintenance of certain financial ratios and certain restrictions with respect to payment of dividends, common stock repurchases, investments, acquisitions, indebtedness and capital expenditures. A commitment fee of 0.5% is payable on the average daily unused amount of the 2010 Revolving Credit Facility. Borrowings under the 2010 Revolving Credit Facility bear interest at (1) a rate which is the prime commercial lending rate announced by Bank of Montreal from time to time (3.25% at March 31, 2011) plus 1.75% to 2.25%, based on certain financial tests or (2) United States dollar LIBOR (0.25% at March 31, 2011) plus 2.75% to 3.25%, based on certain financial tests. The interest rate in effect at March 31, 2011 was 3.00%. Letter of credit fees issued under this facility range from 2.75% to 3.25% of the respective face amounts of the letters of credit issued and are charged based on certain financial tests. In connection with the termination of the Old Revolving Credit Facility, less than $0.1 million was attributable to the acceleration of amortization of debt issuance costs and was recorded as part of interest expense. As of March 31, 2011 and December 31, 2010, we had approximately $89.3 million and $82.4 million of letters of credit outstanding, respectively. We have borrowings of $150.0 million outstanding under the 2010 Revolving Credit Facility at March 31, 2011, which may remain outstanding at our discretion until the 2010 Revolving Credit Facility expires.
On September 19, 2007, we entered into an agreement providing for a $300.0 million term loan (“Term Loan”). The proceeds of the Term Loan were used to pay a portion of the consideration for an acquisition and costs and expenses incident thereto. In connection with the closing of the 2010 Revolving Credit Facility, we proceeded to borrow $150.0 million under this facility and used the proceeds along with cash on hand to prepay on February 4, 2010 all indebtedness outstanding under the Term Loan. In connection with this prepayment, $0.6 million was attributable to the acceleration of amortization of debt issuance costs associated with the Term Loan and was recorded as part of interest expense.
The terms of our construction contracts frequently require that we obtain from surety companies (“Surety Companies”) and provide to our customers payment and performance bonds (“Surety Bonds”) as a condition to the award of such contracts. The Surety Bonds secure our payment and performance obligations under such contracts, and we have agreed to indemnify the Surety Companies for amounts, if any, paid by them in respect of Surety Bonds issued on our behalf. In addition, at the request of labor unions representing certain of our employees, Surety Bonds are sometimes provided to secure obligations for wages and benefits payable to or for such employees. Public sector contracts require Surety Bonds more frequently than private sector contracts, and accordingly, our bonding requirements typically increase as the amount of public sector work increases. As of March 31, 2011, based on our percentage-of-completion of our projects covered by Surety Bonds, our aggregate estimated exposure, assuming defaults on all our then existing contractual obligations, was approximately $1.4 billion. The Surety Bonds are issued by Surety Companies in return for premiums, which vary depending on the size and type of bond.
In recent years, there has been a reduction in the aggregate Surety Bond issuance capacity of Surety Companies due to the economy and the regulatory environment. Consequently, the availability of Surety Bonds has become more limited and the terms upon which Surety Bonds are available have become more restrictive. We continually monitor our available limits of Surety Bonds and discuss with our current and other Surety Bond providers the amount of Surety Bonds that may be available to us based on our financial strength and the absence of any default by us on any Surety Bond issued on our behalf. However, if we experience changes in our bonding relationships or if there are further changes in the surety industry, we may seek to satisfy certain customer requests for Surety Bonds by posting other forms of collateral in lieu of Surety Bonds such as letters of credit or guarantees by EMCOR Group, Inc., by seeking to convince customers to forego the requirement for Surety Bonds, by increasing our activities in business segments that rarely require Surety Bonds such as the facilities services segment, and/or by refraining from bidding for certain projects that require Surety Bonds. There can be no assurance that we will be able to effectuate alternatives to providing Surety Bonds to our customers or to obtain, on favorable terms, sufficient additional work that does not require Surety Bonds to replace projects requiring Surety Bonds that we may decide not to pursue. Accordingly, if we were to experience a reduction in the availability of Surety Bonds, we could experience a material adverse effect on our financial position, results of operations and/or cash flows.

 

22


Table of Contents

We do not have any other material financial guarantees or off-balance sheet arrangements other than those disclosed herein.
Our primary source of liquidity has been, and is expected to continue to be, cash generated by operating activities. We also maintain our 2010 Revolving Credit Facility that may be utilized, among other things, to meet short-term liquidity needs in the event cash generated by operating activities is insufficient or to enable us to seize opportunities to participate in joint ventures or to make acquisitions that may require access to cash on short notice or for any other reason. However, negative macroeconomic trends may have an adverse effect on liquidity. In addition to managing borrowings, our focus on the facilities services market is intended to provide an additional buffer against economic downturns inasmuch as a part of our facilities services business is characterized by annual and multi-year contracts that provide a more predictable stream of cash flow than the construction business. Short-term liquidity is also impacted by the type and length of construction contracts in place. During past economic downturns, there were typically fewer small discretionary projects from the private sector, and companies like us aggressively bid larger long-term infrastructure and public sector contracts. Performance of long duration contracts typically requires greater amounts of working capital. While we strive to maintain a net over-billed position with our customers, there can be no assurance that a net over-billed position can be maintained. Our net over-billings, defined as the balance sheet accounts “Billings in excess of costs and estimated earnings on uncompleted contracts” less “Costs and estimated earnings in excess of billings on uncompleted contracts”, were $346.5 million and $368.4 million as of March 31, 2011 and December 31, 2010, respectively.
Long-term liquidity requirements can be expected to be met initially through cash generated from operating activities and our 2010 Revolving Credit Facility. Based upon our current credit ratings and financial position, we can reasonably expect to be able to incur long-term debt to fund acquisitions. Over the long term, our primary revenue risk factor continues to be the level of demand for non-residential construction services, which is influenced by macroeconomic trends including interest rates and governmental economic policy. In addition, our ability to perform work is critical to meeting long-term liquidity requirements.
We believe that our current cash balances and our borrowing capacity available under the 2010 Revolving Credit Facility or other forms of financing available to us through borrowings, combined with cash expected to be generated from operations, will be sufficient to provide our short-term and foreseeable long-term liquidity and meet our expected capital expenditure requirements. However, we are a party to lawsuits and other proceedings in which other parties seek to recover from us amounts ranging from a few thousand dollars to over $40.0 million. If we were required to pay damages in one or more such proceedings, such payments could have a material adverse effect on our financial position, results of operations and/or cash flows.
Certain Insurance Matters
As of March 31, 2011 and December 31, 2010, we utilized approximately $89.0 million and $82.2 million, respectively, of letters of credit obtained under our 2010 Revolving Credit Facility as collateral for our insurance obligations.
New Accounting Pronouncements
We review new accounting standards to determine the expected financial impact, if any, that the adoption of such standards will have. As of the filing of this Quarterly Report on Form 10-Q, there were no new accounting standards that were projected to have a material impact on our consolidated financial position, results of operations or liquidity. Refer to Part I, Item 1, “Financial Statements — Notes to Condensed Consolidated Financial Statements — Note 2, New Accounting Pronouncements”, for further information regarding new accounting standards.

 

23


Table of Contents

Application of Critical Accounting Policies
Our condensed consolidated financial statements are based on the application of significant accounting policies, which require management to make significant estimates and assumptions. Our significant accounting policies are described in Note 2 — Summary of Significant Accounting Policies of the notes to consolidated financial statements included in Item 8 of the annual report on Form 10-K for the year ended December 31, 2010. We adopted three new accounting pronouncements during the three months ended March 31, 2011 (see Note 2, “New Accounting Pronouncements”, for further information). We believe that some of the more critical judgment areas in the application of accounting policies that affect our financial condition and results of operations are the impact of changes in the estimates and judgments pertaining to: (a) revenue recognition from (i) long-term construction contracts for which the percentage-of-completion method of accounting is used and (ii) services contracts; (b) collectibility or valuation of accounts receivable; (c) insurance liabilities; (d) income taxes; and (e) goodwill and identifiable intangible assets.
Revenue Recognition for Long-term Construction Contracts and Services Contracts
We believe our most critical accounting policy is revenue recognition from long-term construction contracts for which we use the percentage-of-completion method of accounting. Percentage-of-completion accounting is the prescribed method of accounting for long-term contracts in accordance with Accounting Standard Codification (“ASC”) Topic 605-35, “Revenue Recognition — Construction-Type and Production-Type Contracts”, and, accordingly, is the method used for revenue recognition within our industry. Percentage-of-completion is measured principally by the percentage of costs incurred to date for each contract to the estimated total costs for such contract at completion. Certain of our electrical contracting business units and our Canadian subsidiary measure percentage-of-completion by the percentage of labor costs incurred to date for each contract to the estimated total labor costs for such contract. Provisions for the entirety of estimated losses on uncompleted contracts are made in the period in which such losses are determined. Application of percentage-of-completion accounting results in the recognition of costs and estimated earnings in excess of billings on uncompleted contracts in our Condensed Consolidated Balance Sheets. Costs and estimated earnings in excess of billings on uncompleted contracts reflected in the Condensed Consolidated Balance Sheets arise when revenues have been recognized but the amounts cannot be billed under the terms of contracts. Such amounts are recoverable from customers upon various measures of performance, including achievement of certain milestones, completion of specified units or completion of a contract.
Costs and estimated earnings in excess of billings on uncompleted contracts also include amounts we seek or will seek to collect from customers or others for errors or changes in contract specifications or design, contract change orders in dispute or unapproved as to both scope and price or other customer-related causes of unanticipated additional contract costs (claims and unapproved change orders). Such amounts are recorded at estimated net realizable value and take into account factors that may affect our ability to bill unbilled revenues and collect amounts after billing. The profit associated with claim amounts is not recognized until the claim has been settled and payment has been received. Due to uncertainties inherent in estimates employed in applying percentage-of-completion accounting, estimates may be revised as project work progresses. Application of percentage-of-completion accounting requires that the impact of revised estimates be reported prospectively in the condensed consolidated financial statements. In addition to revenue recognition for long-term construction contracts, we recognize revenues from the performance of facilities services for maintenance, repair and retrofit work consistent with the performance of services, which are generally on a pro-rata basis over the life of the contractual arrangement. Expenses related to all services arrangements are recognized as incurred. Revenues related to the engineering, manufacturing and repairing of shell and tube heat exchangers are recognized when the product is shipped and all other revenue recognition criteria have been met. Costs related to this work are included in inventory until the product is shipped. These costs include all direct material, labor and subcontracting costs and indirect costs related to performance such as supplies, tools and repairs.

 

24


Table of Contents

Accounts Receivable
We are required to estimate the collectibility of accounts receivable. A considerable amount of judgment is required in assessing the likelihood of realization of receivables. Relevant assessment factors include the creditworthiness of the customer, our prior collection history with the customer and related aging of the past due balances. The recovery of doubtful accounts during the three months ended March 31, 2011 decreased by $0.4 million compared to the three months ended March 31, 2010. This decrease was due to a reduction in the recovery of amounts previously determined to be uncollectible. At March 31, 2011 and December 31, 2010, our accounts receivable of $1,103.2 million and $1,090.9 million, respectively, included allowances for doubtful accounts of $17.2 million and $17.3 million, respectively. Specific accounts receivable are evaluated when we believe a customer may not be able to meet its financial obligations due to deterioration of its financial condition or its credit ratings. The allowance for doubtful accounts requirements are based on the best facts available and are re-evaluated and adjusted on a regular basis as additional information is received.
Insurance Liabilities
We have loss payment deductibles for certain workers’ compensation, automobile liability, general liability and property claims, have self-insured retentions for certain other casualty claims and are self-insured for employee-related healthcare claims. Losses are recorded based upon estimates of our liability for claims incurred and for claims incurred but not reported. The liabilities are derived from known facts, historical trends and industry averages utilizing the assistance of an actuary to determine the best estimate for the majority of these obligations. We believe the liabilities recognized on our balance sheets for these obligations are adequate. However, such obligations are difficult to assess and estimate due to numerous factors, including severity of injury, determination of liability in proportion to other parties, timely reporting of occurrences and effectiveness of safety and risk management programs. Therefore, if our actual experience differs from the assumptions and estimates used for recording the liabilities, adjustments may be required and will be recorded in the period that the experience becomes known.
Income Taxes
We had net deferred income tax liabilities at March 31, 2011 of $9.9 million and net deferred income tax assets at December 31, 2010 of $5.2 million, primarily resulting from differences between the carrying value and income tax basis of certain depreciable fixed assets and identifiable intangible assets, which will impact our taxable income in future periods. A valuation allowance is required when it is more likely than not that all or a portion of a deferred income tax asset will not be realized. As of March 31, 2011 and December 31, 2010, the total valuation allowance on gross deferred income tax assets was approximately $3.7 million and $0.8 million, respectively.
Goodwill and Identifiable Intangible Assets
As of March 31, 2011, we had $426.7 million and $259.4 million, respectively, of goodwill and net identifiable intangible assets (primarily consisting of our contract backlog, developed technology, customer relationships, non-competition agreements and trade names), primarily arising out of the acquisition of companies. As of December 31, 2010, goodwill and net identifiable intangible assets were $406.8 million and $245.1 million, respectively. The changes to goodwill and net identifiable intangible assets (net of accumulated amortization) since December 31, 2010 were related to: (a) the acquisition of a company during the first quarter of 2011 and (b) the finalization of the purchase price accounting for an acquisition of a company during the fourth quarter of 2010. The determination of related estimated useful lives for identifiable intangible assets and whether those assets are impaired involves significant judgments based upon short and long-term projections of future performance. These forecasts reflect assumptions regarding the ability to successfully integrate acquired companies, as well as macroeconomic conditions. ASC Topic 350, “Intangibles—Goodwill and Other” (“ASC 350”) requires goodwill and other identifiable intangible assets with indefinite useful lives not be amortized, but instead must be tested at least annually for impairment (which we test each October 1, absent any impairment indicators), and be written down if impaired. ASC 350 requires that goodwill be allocated to its respective reporting unit and that identifiable intangible assets with finite lives be amortized over their useful lives.
We test for impairment of goodwill at the reporting unit level utilizing the two-step process as prescribed by ASC 350. The first step of this test compares the fair value of the reporting unit, determined based upon discounted estimated future cash flows, to the carrying amount, including goodwill. If the fair value exceeds the carrying amount, no further work is required and no impairment loss is recognized. If the carrying amount of the reporting unit exceeds the fair value, the goodwill of the reporting unit is potentially impaired and step two of the goodwill impairment test would need to be performed to measure the amount of an impairment loss, if any. In the second step, the impairment is computed by comparing the implied fair value of the reporting unit’s goodwill with the carrying amount of the goodwill. If the carrying amount of the reporting unit’s goodwill is greater than the implied fair value of its goodwill, an impairment loss in the amount of the excess is recognized and charged to operations. For the year ended December 31, 2010, we recognized a $210.6 million non-cash goodwill impairment charge. No impairment of our goodwill was recognized for either of the three month periods ended March 31, 2011 and 2010.

 

25


Table of Contents

We also test for the impairment of trade names that are not subject to amortization by calculating the fair value using the “relief from royalty payments” methodology. This approach involves two steps: (a) estimating reasonable royalty rates for each trade name and (b) applying these royalty rates to a net revenue stream and discounting the resulting cash flows to determine fair value. This fair value is then compared with the carrying value of each trade name. If the carrying amount of the trade name is greater than the implied fair value of the trade name, an impairment in the amount of the excess is recognized and charged to operations. As a result of the continued assessment of the fair value of trade names previously impaired in 2009 and the interim impairment testing performed during the second and third quarters of 2010, we recorded an additional $35.5 million non-cash impairment charge of trade names associated with certain prior acquisitions during 2010. These trade names are reported within our United States facilities services segment. No additional impairment of our trade names was recognized for either of the three month periods ended March 31, 2011 and 2010.
In addition, we review for the impairment of other identifiable intangible assets that are being amortized whenever facts and circumstances indicate that their carrying values may not be fully recoverable. This test compares their carrying values to the undiscounted pre-tax cash flows expected to result from the use of the assets. If the assets are impaired, the assets are written down to their fair values, generally determined based on their future discounted cash flows. For either of the three month periods ended March 31, 2011 and 2010, or for the year ended December 31, 2010, no impairment of our other identifiable intangible assets was recognized.
As of March 31, 2011, we had $426.7 million of goodwill on our balance sheet and, of this amount, approximately 53.8% relates to our United States facilities services segment, approximately 45.3% relates to our United States mechanical construction and facilities services segment and approximately 0.9% relates to our United States electrical construction and facilities services segment. As of the date of our latest impairment test, October 1, 2010, the fair values of our United States facilities services, United States mechanical construction and facilities services and United States electrical construction and facilities services segments exceeded their respective carrying values by approximately $50.6 million, $301.6 million and $337.8 million, respectively. The weighted average cost of capital used in testing goodwill for impairment was 13.2% and 12.2% for our domestic construction and facilities services segments and our United States facilities services segment, respectively. The perpetual growth rate used was 3.0% for our domestic construction segments and 2.8% for our United States facilities services segment, respectively.
Our development of the present value of future cash flow projections used in impairment testing is based upon assumptions and estimates by management derived from a review of our operating results, business plans, anticipated growth rates and margins and weighted average cost of capital, among others. Much of the information used in assessing fair value is outside the control of management, such as interest rates, and these assumptions and estimates can change in future periods. There can be no assurances that our estimates and assumptions made for purposes of our goodwill and identifiable intangible asset impairment testing as of October 1, 2010 will prove to be accurate predictions of the future. If our assumptions regarding business plans or anticipated growth rates and/or margins are not achieved, or there is a rise in interest rates, we may be required to record further goodwill and/or identifiable intangible asset impairment charges in future periods.
Although we have not yet conducted our October 1, 2011 goodwill and other impairment tests, there have been no impairments recognized through the first three months of 2011. It is not possible at this time to determine if any such future impairment charge would result or, if it does, whether such a charge would be material.

 

26


Table of Contents

ITEM 3.  
QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK.
We have not used any derivative financial instruments during the three months ended March 31, 2011, including trading or speculating on changes in commodity prices of materials used in our business.
We are exposed to market risk for changes in interest rates for borrowings under the 2010 Revolving Credit Facility and were exposed to market risk as it related to the interest rate swap. Borrowings under the 2010 Revolving Credit Facility bear interest at variable rates. As of March 31, 2011, there were borrowings of $150.0 million outstanding under the 2010 Revolving Credit Facility. This instrument bears interest at (1) a rate which is the prime commercial lending rate announced by Bank of Montreal from time to time (3.25% at March 31, 2011) plus 1.75% to 2.25% based on certain financial tests or (2) United States dollar LIBOR (0.25% at March 31, 2011) plus 2.75% to 3.25% based on certain financial tests. The interest rate in effect at March 31, 2011 was 3.00%. Based on the $150.0 million borrowings outstanding on the 2010 Revolving Credit Facility, if overall interest rates were to increase by 25 basis points, interest expense, net of income taxes, would increase by approximately $0.2 million in the next twelve months. Conversely, if overall interest rates were to decrease by 25 basis points, interest expense, net of income taxes, would decrease by approximately $0.2 million in the next twelve months. Letter of credit fees issued under this facility range from 2.75% to 3.25% of the respective face amounts of the letters of credit issued and are charged based on certain financial tests. The 2010 Revolving Credit Facility expires in February 2013. There is no guarantee that we will be able to renew the 2010 Revolving Credit Facility at its expiration.
We are also exposed to construction market risk and its potential related impact on accounts receivable or costs and estimated earnings in excess of billings on uncompleted contracts. The amounts recorded may be at risk if our customers’ ability to pay these obligations is negatively impacted by economic conditions. We continually monitor the creditworthiness of our customers and maintain on-going discussions with customers regarding contract status with respect to change orders and billing terms. Therefore, we believe we take appropriate action to manage market and other risks, but there is no assurance that we will be able to reasonably identify all risks with respect to collectibility of these assets. See also the previous discussion of Accounts Receivable under the heading, “Application of Critical Accounting Policies” in Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations.
Amounts invested in our foreign operations are translated into U.S. dollars at the exchange rates in effect at the end of the period. The resulting translation adjustments are recorded as accumulated other comprehensive income (loss), a component of equity, in our Condensed Consolidated Balance Sheets. We believe the exposure to the effects that fluctuating foreign currencies may have on our consolidated results of operations is limited because the foreign operations primarily invoice customers and collect obligations in their respective local currencies. Additionally, expenses associated with these transactions are generally contracted and paid for in their same local currencies.
In addition, we are exposed to market risk of fluctuations in certain commodity prices of materials, such as copper and steel, which are used as components of supplies or materials utilized in both our construction and facilities services operations. We are also exposed to increases in energy prices, particularly as they relate to gasoline prices for our fleet of over 8,000 vehicles. While we believe we can increase our prices to adjust for some price increases in commodities, there can be no assurance that price increases of all commodities, if they were to occur, would be recoverable.

 

27


Table of Contents

ITEM 4.  
CONTROLS AND PROCEDURES.
Based on an evaluation of our disclosure controls and procedures (as required by Rule 13a-15(b) of the Securities Exchange Act of 1934), our President and Chief Executive Officer, Anthony J. Guzzi, and our Executive Vice President and Chief Financial Officer, Mark A. Pompa, have concluded that our disclosure controls and procedures (as defined in Rule 13a-15(e) of the Securities Exchanges Act of 1934) are effective as of the end of the period covered by this report.
There have not been any changes in the Company’s internal control over financial reporting (as such term is defined in Rules 13a-15(f) and 15(d)-15(f) under the Securities Exchange Act of 1934) during the fiscal quarter ended March 31, 2011 that have materially affected, or are reasonably likely to materially affect, the Company’s internal control over financial reporting.
PART II. — OTHER INFORMATION.
ITEM 1.  
LEGAL PROCEEDINGS.
In our Form 10-K for the year ended December 31, 2010, we continued to report a claim made in an arbitration proceeding on March 14, 2003 by John Mowlem Construction plc (“Mowlem”) against our United Kingdom subsidiary, EMCOR Group (UK) plc (“EMCOR UK”), in connection with a subcontract EMCOR UK entered into with Mowlem with respect to a project for the United Kingdom Ministry of Defence. In the arbitration proceeding, Mowlem sought damages from EMCOR UK of approximately 38.5 million British pounds sterling (approximately $61.8 million) arising out of the electrical and mechanical engineering services EMCOR UK provided for the project. In that proceeding, EMCOR UK asserted a counterclaim for approximately 11.6 million British pounds sterling (approximately $18.6 million) for certain design, labor, and delay and disruption costs incurred by EMCOR UK in connection with the subcontract with Mowlem. On March 31, 2011, EMCOR UK, Mowlem, and Mowlem’s successors in interest settled all claims arising out of this matter, discontinued all related proceedings, and executed mutual releases.
ITEM 6.  
EXHIBITS.
For the list of exhibits, see the Exhibit Index immediately following the signature page hereof, which Exhibit Index is incorporated herein by reference.

 

28


Table of Contents

SIGNATURES
Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
         
Date: April 28, 2011  EMCOR GROUP, INC.
(Registrant)
 
 
  By:   /s/ ANTHONY J. GUZZI    
    Anthony J. Guzzi   
    President and Chief Executive Officer
(Principal Executive Officer) 
 
     
  By:   /s/ MARK A. POMPA    
    Mark A. Pompa   
    Executive Vice President and Chief Financial Officer
(Principal Financial and Accounting Officer) 
 

 

29


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
   
 
   
2(a-1)  
Purchase Agreement dated as of February 11, 2002 by and among Comfort Systems USA, Inc. and EMCOR-CSI Holding Co.
  Exhibit 2.1 to EMCOR Group, Inc.’s (“EMCOR”) Report on Form 8-K dated February 14, 2002
   
 
   
2(a-2)  
Purchase and Sale Agreement dated as of August 20, 2007 between FR X Ohmstede Holdings LLC and EMCOR Group, Inc.
  Exhibit 2.1 to EMCOR’s Report on Form 8-K (Date of Report August 20, 2007)
   
 
   
3(a-1)  
Restated Certificate of Incorporation of EMCOR filed December 15, 1994
  Exhibit 3(a-5) to EMCOR’s Registration Statement on Form 10 as originally filed March 17, 1995 (“Form 10”)
   
 
   
3(a-2)  
Amendment dated November 28, 1995 to the Restated Certificate of Incorporation of EMCOR
  Exhibit 3(a-2) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 1995 (“1995 Form 10-K”)
   
 
   
3(a-3)  
Amendment dated February 12, 1998 to the Restated Certificate of Incorporation of EMCOR
  Exhibit 3(a-3) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 1997 (“1997 Form 10-K”)
   
 
   
3(a-4)  
Amendment dated January 27, 2006 to the Restated Certificate of Incorporation of EMCOR
  Exhibit 3(a-4) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2005 (“2005 Form 10-K”)
   
 
   
3(a-5)  
Amendment dated September 18, 2007 to the Restated Certificate of Incorporation of EMCOR
  Exhibit A to EMCOR’s Proxy Statement dated August 17, 2007 for Special Meeting of Stockholders held September 18, 2007
   
 
   
3(b)  
Amended and Restated By-Laws
  Exhibit 3(b) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 1998 (“1998 Form 10-K”)
   
 
   
4(a)  
Second Amended and Restated Credit Agreement dated as of February 4, 2010 by and among EMCOR Group, Inc. and certain of its subsidiaries and Bank of Montreal, individually and as Agent and the Lenders which are or become parties thereto (the “Credit Agreement”)
  Exhibit 4.1(a) to EMCOR’s Report on Form 8-K (Date of Report February 4, 2010) (“February 2010 Form 8-K”)
   
 
   
4(b)  
Third Amended and Restated Security Agreement dated as of February 4, 2010 among EMCOR, certain of its U.S. subsidiaries, and Bank of Montreal, as Agent
  Exhibit 4.1(b) to the February 2010 Form 8-K
   
 
   
4(c)  
Third Amended and Restated Pledge Agreement dated as of February 4, 2010 among EMCOR, certain of its U.S. subsidiaries, and Bank of Montreal, as Agent
  Exhibit 4.1(c) to the February 2010 Form 8-K
   
 
   
4(d)  
Second Amended and Restated Guaranty Agreement dated as of February 4, 2010 by certain of EMCOR’s U.S. subsidiaries in favor of Bank of Montreal, as Agent
  Exhibit 4.1(d) to the February 2010 Form 8-K
   
 
   
10(a)  
Form of Severance Agreement (“Severance Agreement”) between EMCOR and each of Sheldon I. Cammaker, R. Kevin Matz and Mark A. Pompa
  Exhibit 10.1 to the April 2005 Form 8-K
   
 
   
10(b)  
Form of Amendment to Severance Agreement between EMCOR and each of Sheldon I. Cammaker, R. Kevin Matz and Mark A. Pompa
  Exhibit 10(c) to EMCOR’s Quarterly Report on Form 10-Q for the quarter ended March 31, 2007 (“March 2007 Form 10-Q”)
   
 
   
10(c)  
Letter Agreement dated October 12, 2004 between Anthony Guzzi and EMCOR (the “Guzzi Letter Agreement”)
  Exhibit 10.1 to EMCOR’s Report on Form 8-K (Date of Report October 12, 2004)

 

30


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
 
10(d)  
Form of Confidentiality Agreement between Anthony Guzzi and EMCOR
  Exhibit C to the Guzzi Letter Agreement
   
 
   
10(e)  
Form of Indemnification Agreement between EMCOR and each of its officers and directors
  Exhibit F to the Guzzi Letter Agreement
   
 
   
10(f-1)  
Severance Agreement (“Guzzi Severance Agreement”) dated October 25, 2004 between Anthony Guzzi and EMCOR
  Exhibit D to the Guzzi Letter Agreement
   
 
   
10(f-2)  
Amendment to Guzzi Severance Agreement
  Exhibit 10(g-2) to the March 2007 Form 10-Q
   
 
   
10(g-1)  
1994 Management Stock Option Plan (“1994 Option Plan”)
  Exhibit 10(o) to Form 10
   
 
   
10(g-2)  
Amendment to Section 12 of the 1994 Option Plan
  Exhibit (g-2) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2000 (“2000 Form 10-K”)
   
 
   
10(g-3)  
Amendment to Section 13 of the 1994 Option Plan
  Exhibit (g-3) to 2000 Form 10-K
   
 
   
10(h-1)  
1995 Non-Employee Directors’ Non-Qualified Stock Option Plan (“1995 Option Plan”)
  Exhibit 10(p) to Form 10
   
 
   
10(h-2)  
Amendment to Section 10 of the 1995 Option Plan
  Exhibit (h-2) to 2000 Form 10-K
   
 
   
10(i-1)  
1997 Non-Employee Directors’ Non-Qualified Stock Option Plan (“1997 Option Plan”)
  Exhibit 10(k) to 1998 Form 10-K
   
 
   
10(i-2)  
Amendment to Section 9 of the 1997 Option Plan
  Exhibit 10(i-2) to 2000 Form 10-K
   
 
   
10(j-1)  
Continuity Agreement dated as of June 22, 1998 between Sheldon I. Cammaker and EMCOR (“Cammaker Continuity Agreement”)
  Exhibit 10(c) to the June 1998 Form 10-Q
   
 
   
10(j-2)  
Amendment dated as of May 4, 1999 to Cammaker Continuity Agreement
  Exhibit 10(i) to the June 1999 Form 10-Q
   
 
   
10(j-3)  
Amendment dated as of March 1, 2007 to Cammaker Continuity Agreement
  Exhibit 10(m-3) to the March 2007 Form 10-Q
   
 
   
10(k-1)  
Continuity Agreement dated as of June 22, 1998 between R. Kevin Matz and EMCOR (“Matz Continuity Agreement”)
  Exhibit 10(f) to the June 1998 Form 10-Q
   
 
   
10(k-2)  
Amendment dated as of May 4, 1999 to Matz Continuity Agreement
  Exhibit 10(m) to the June 1999 Form 10-Q
   
 
   
10(k-3)  
Amendment dated as of January 1, 2002 to Matz Continuity Agreement
  Exhibit 10(o-3) to EMCOR’s Quarterly Report on Form 10-Q for the quarter ended March 31, 2002 (“March 2002 Form 10-Q”)
   
 
   
10(k-4)  
Amendment dated as of March 1, 2007 to Matz Continuity Agreement
  Exhibit 10(n-4) to the March 2007 Form 10-Q
   
 
   
10(l-1)  
Continuity Agreement dated as of June 22, 1998 between Mark A. Pompa and EMCOR (“Pompa Continuity Agreement”)
  Exhibit 10(g) to the June 1998 Form 10-Q
   
 
   
10(l-2)  
Amendment dated as of May 4, 1999 to Pompa Continuity Agreement
  Exhibit 10(n) to the June 1999 Form 10-Q
   
 
   
10(l-3)  
Amendment dated as of January 1, 2002 to Pompa Continuity Agreement
  Exhibit 10(p-3) to the March 2002 Form 10-Q

 

31


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
 
10(l-4)  
Amendment dated as of March 1, 2007 to Pompa Continuity Agreement
  Exhibit 10(o-4) to the March 2007 Form 10-Q
   
 
   
10(m-1)  
Change of Control Agreement dated as of October 25, 2004 between Anthony Guzzi (“Guzzi”) and EMCOR (“Guzzi Continuity Agreement”)
  Exhibit E to the Guzzi Letter Agreement
   
 
   
10(m-2)  
Amendment dated as of March 1, 2007 to Guzzi Continuity Agreement
  Exhibit 10(p-2) to the March 2007 Form 10-Q
   
 
   
10(n-1)  
Amendment dated as of March 29, 2010 to Severance Agreement with Sheldon I. Cammaker, Anthony J. Guzzi, R. Kevin Matz and Mark A. Pompa
  Exhibit 10.1 to Form 8-K (Date of Report March 29, 2010) (“March 2010 Form 8-K”)
   
 
   
10(n-2)  
Amendment to Continuity Agreements and Severance Agreements with Sheldon I. Cammaker, Anthony J. Guzzi, R. Kevin Matz and Mark A. Pompa
  Exhibit 10(q) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2008 (“2008 Form 10-K”)
   
 
   
10(o)  
Letter Agreement dated May 25, 2010 between EMCOR and Frank T. MacInnis
  Exhibit 10.1 to EMCOR’s Report on Form 8-K (Date of Report May 25, 2010)
   
 
   
10(p-1)  
Incentive Plan for Senior Executive Officers of EMCOR Group, Inc. (“Incentive Plan for Senior Executives”)
  Exhibit 10.3 to Form 8-K (Date of Report March 4, 2005)
   
 
   
10(p-2)  
First Amendment to Incentive Plan for Senior Executives
  Exhibit 10(t) to 2005 Form 10-K
   
 
   
10(p-3)  
Amendment made February 27, 2008 to Incentive Plan for Senior Executive Officers
  Exhibit 10(r-3) to 2008 Form 10-K
   
 
   
10(p-4)  
Amendment made December 22, 2008 to Incentive Plan for Senior Executive Officers
  Exhibit 10(r-4) to 2008 Form 10-K
   
 
   
10(p-5)  
Amendment made December 15, 2009 to Incentive Plan for Senior Executive Officers
  Exhibit 10(r-5) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2009 (“2009 Form 10-K”)
   
 
   
10(p-6)  
Suspension of Incentive Plan for Senior Executive Officers
  Exhibit 10(r-5) to 2008 Form 10-K
   
 
   
10(q-1)  
EMCOR Group, Inc. Long-Term Incentive Plan (“LTIP”)
  Exhibit 10 to Form 8-K (Date of Report December 15, 2005)
   
 
   
10(q-2)  
First Amendment to LTIP and updated Schedule A to LTIP
  Exhibit 10(s-2) to 2008 Form 10-K
   
 
   
10(q-3)  
Second Amendment to LTIP
  Exhibit 10.2 to March 2010 Form 8-K
   
 
   
10(q-4)  
Form of Certificate Representing Stock Units issued under LTIP
  Exhibit 10(t-2) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2007 (“2007 Form 10-K”)
   
 
   
10(r-1)  
2003 Non-Employee Directors’ Stock Option Plan
  Exhibit A to EMCOR’s Proxy Statement for its Annual Meeting held on June 12, 2003 (“2003 Proxy Statement”)
   
 
   
10(r-2)  
First Amendment to 2003 Non-Employee Directors’ Plan
  Exhibit A to EMCOR’s Proxy Statement for its Annual Meeting held on June 12, 2003 (“2003 Proxy Statement”)
   
 
   
10(s-1)  
2003 Management Stock Incentive Plan
  Exhibit B to EMCOR’s 2003 Proxy Statement

 

32


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
 
10(s-2)  
Amendments to 2003 Management Stock Incentive Plan
  Exhibit 10(t-2) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2003 (“2003 Form 10-K”)
   
 
   
10(s-3)  
Second Amendment to 2003 Management Stock Incentive Plan
  Exhibit 10(v-3) to 2006 Form 10-K
   
 
   
10(t)  
Form of Stock Option Agreement evidencing grant of stock options under the 2003 Management Stock Incentive Plan
  Exhibit 10.1 to Form 8-K (Date of Report January 3, 2005)
   
 
   
10(u)  
Key Executive Incentive Bonus Plan
  Exhibit B to EMCOR’s Proxy Statement for its Annual Meeting held June 18, 2008 (“2008 Proxy Statement”)
   
 
   
10(v)  
2005 Management Stock Incentive Plan
  Exhibit B to EMCOR’s Proxy Statement for its Annual Meeting held June 16, 2005 (“2005 Proxy Statement”)
   
 
   
10(w)  
First Amendment to 2005 Management Stock Incentive Plan
  Exhibit 10(z) to 2006 Form 10-K
   
 
   
10(x-1)  
2005 Stock Plan for Directors
  Exhibit C to 2005 Proxy Statement
   
 
   
10(x-2)  
First Amendment to 2005 Stock Plan for Directors
  Exhibit 10(a)(a-2) to 2006 Form 10-K
   
 
   
10(x-3)  
Consents on December 15, 2009 to Transfer Stock Options by Non-Employee Directors
  Exhibit 10(z) to 2009 Form 10-K
   
 
   
10(y)  
Option Agreement between EMCOR and Frank T. MacInnis dated May 5, 1999
  Exhibit 4.4 to 2004 Form S-8 (Date of Report February 18, 2004) (“2004 Form S-8”)
   
 
   
10(z)  
Form of EMCOR Option Agreement for Messrs. Frank T. MacInnis, Sheldon I. Cammaker, R. Kevin Matz and Mark A. Pompa (collectively the “Executive Officers”) for options granted January 4, 1999, January 3, 2000 and January 2, 2001
  Exhibit 4.5 to 2004 Form S-8
   
 
   
10(a)(a)  
Form of EMCOR Option Agreement for Executive Officers granted December 14, 2001
  Exhibit 4.6 to 2004 Form S-8
   
 
   
10(b)(b)  
Form of EMCOR Option Agreement for Executive Officers granted January 2, 2002, January 2, 2003 and January 2, 2004
  Exhibit 4.7 to 2004 Form S-8
   
 
   
10(c)(c)  
Form of EMCOR Option Agreement for Directors granted June 19, 2002, October 25, 2002 and February 27, 2003
  Exhibit 4.8 to 2004 Form S-8
   
 
   
10(d)(d)  
Option Agreement dated October 25, 2004 between Guzzi and EMCOR
  Exhibit A to Guzzi Letter
   
 
   
10(e)(e-1)  
2007 Incentive Plan
  Exhibit B to EMCOR’s Proxy Statement for its Annual Meeting held June 20, 2007
   
 
   
10(e)(e-2)  
Option Agreement dated December 13, 2007 under 2007 Incentive Plan between Jerry E. Ryan and EMCOR
  Exhibit 10(h)(h-2) to 2007 Form 10-K
   
 
   
10(e)(e-3)  
Option Agreement dated December 15, 2008 under 2007 Incentive Plan between David Laidley and EMCOR
  Exhibit 10.1 to Form 8-K (Date of Report December 15, 2008)

 

33


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
 
10(e)(e-4)  
Form of Option Agreement under 2007 Incentive Plan between EMCOR and each non-employee director electing to receive options as part of annual retainer
  Exhibit 10(h)(h-3) to 2007 Form 10-K
   
 
   
10(f)(f-1)  
2010 Incentive Plan
  Exhibit B to EMCOR’s Proxy Statement for its Annual Meeting held on June 11, 2010
   
 
   
10(f)(f-2)  
Form of Option Agreement under 2010 Incentive Plan between EMCOR and each non-employee director with respect to grant of options upon re-election at June 11, 2010 Annual Meeting of Stockholders
  Exhibit 10(i)(i-2) to EMCOR’s Quarterly Report on Form 10-Q for the quarter ended June 30, 2010
   
 
   
10(g)(g)  
Form of letter agreement between EMCOR and each Executive Officer with respect to acceleration of options granted January 2, 2003 and January 2, 2004
  Exhibit 10(b)(b) to 2004 Form 10-K
   
 
   
10(h)(h)  
EMCOR Group, Inc. Employee Stock Purchase Plan
  Exhibit C to EMCOR’s Proxy Statement for its Annual Meeting held June 18, 2008
   
 
   
10(i)(i-1)  
Certificate dated March 24, 2008 evidencing Phantom Stock Unit Award to Frank T. MacInnis
  Exhibit 10(j)(j-1) to EMCOR’s Quarterly Report on Form 10-Q for the quarter ended March 31, 2008 (“March 2008 Form 10-Q”)
   
 
   
10(i)(i-2)  
Certificate dated March 24, 2008 evidencing Phantom Stock Unit Award to Anthony J. Guzzi
  Exhibit 10(j)(j-2) to the March 2008 Form 10-Q
   
 
   
10(j)(j)  
Certificate dated March 24, 2008 evidencing Stock Unit Award to Frank T. MacInnis
  Exhibit 10(k)(k) to the March 2008 Form 10-Q
   
 
   
10(k)(k)  
Form of Restricted Stock Award Agreement dated January 4, 2010 between EMCOR and each of Albert Fried, Jr., Richard F. Hamm, Jr., David H. Laidley, Jerry E. Ryan and Michael T. Yonker
  Exhibit 10(l)(l) to 2009 Form 10-K
   
 
   
10(l)(l)  
Form of Restricted Stock Award Agreement dated January 3, 2011 between EMCOR and each of Richard F. Hamm, Jr., David H. Laidley, Jerry E. Ryan and Michael T. Yonker
  Exhibit 10(l)(l) to EMCOR’s Annual Report on Form 10-K for the year ended December 31, 2010
   
 
   
11  
Computation of Basic EPS and Diluted EPS for the three months ended March 31, 2011 and 2010
  Note 4 of the Notes to the Condensed Consolidated Financial Statements
   
 
   
31.1  
Certification Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 by Anthony J. Guzzi, the President and Chief Executive Officer *
  Page _____
   
 
   
31.2  
Certification Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 by Mark A. Pompa, the Executive Vice President and Chief Financial Officer *
  Page _____
   
 
   
32.1  
Certification Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 by the President and Chief Executive Officer **
  Page _____
   
 
   
32.2  
Certification Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 by the Executive Vice President and Chief Financial Officer **
  Page _____

 

34


Table of Contents

EXHIBIT INDEX
         
Exhibit       Incorporated By Reference to or
No.   Description   Page Number
 
101  
The following materials from EMCOR Group, Inc.’s Quarterly Report on Form 10-Q for the quarter ended March 31, 2011, formatted in XBRL (Extensible Business Reporting Language): (i) the Condensed Consolidated Balance Sheets, (ii) the Condensed Consolidated Statements of Operations, (iii) the Condensed Consolidated Statements of Cash Flows, (iv) the Condensed Consolidated Statements of Equity and Comprehensive Income and (v) the Notes to Condensed Consolidated Financial Statements, tagged as blocks of text.***
  Page _____
 
*  
Filed Herewith
 
**  
Furnished Herewith
 
***  
Submitted Electronically Herewith
The XBRL related information in Exhibit 101 to this Quarterly Report on Form 10-Q shall not be deemed to be “filed” for purposes of Section 18 of the Exchange Act, or otherwise subject to the liability of that section, and shall not be part of any registration statement or other document filed under the Securities Act or the Exchange Act, except as shall be expressly set forth by specific reference in such filing.

 

35